Skip to content

News - By: Michael Curtis QC



Time For Completion, Concurrent Delay & Adyard Abu Dhabi v SD Marine Services

Articles | 10th May 2011

In the attached article, Michael Curtis QC discusses the the approach taken by the English authorities (including the recent case of Adyard Abu Dhabi v SD Marine Services). It suggests the explanation to the question whether a contractor is entitled to an extension of time where there is delay (including “concurrent delay”) can be found […]

Inconsistent authorities in the Court of Appeal?

Articles | 4th Apr 2011

Is Robinson v PE Jones (Contractors) Ltd [2010] EWCA Civ 9 inconsistent with Barclays Bank Plc v Fairclough Building Ltd & Others (1995) 76 BLR 1? Please click here to view the article by Michael Curtis QC.


Portfolio close
Title Type CV Email

Remove All

Download


Click here to email this list.